|HARDSCAPE GUARANTEE |
Our retaining walls, paver patios, steps, and edging will be guaranteed from defects for 1 year from date of installation.
Because we have little control over preexisting site conditions, we cannot assume responsibility for settling on any construction site.
For example we cannot guarantee damage caused by but not limited to:
Ziegler's Landscape By Design will not be responsible for damage caused to unmarked utilities not covered by DIGGERS HOTLINE! Utilities such as irrigation pipes and wires, invisible fencing, electrical feeds to outbuildings, landscape lighting, ponds, fountains or accessories, etc. are considered 'personal' lines and will not be covered by DIGGERS HOTLINE! Repair costs to such ' personal ' lines are the homeowners responsibility.NOTICE OF LIEN RIGHTS
As required by Wisconsin construction lien law, Ziegler's Landscape By Design hereby notifies you that persons or companies furnishing labor or materials for construction on your land may have lien rights on your land and buildings if not paid. Those entitled to lien rights in addition to Ziegler's Landscape By Design include any who contract directly with you or those who give you notice 60 days after they first furnish labor or materials for your construction. Any notices received should be copied and given to your mortgage lender, if applicable. We agree to cooperate with you and your lender, if any, to see all potential lien claimants are duly paid.
Are you taking CARE of your investment? Let us take care of it for you.
Ziegler's Landscape By Design offers a variety of quality maintenance services aimed at keeping your lawn and landscape looking its very best.
TO OUR CUSTOMERS.Ziegler's Landscape By Design is a well respected nursery dealer and landscape contractor serving western Wisconsin. We are dedicated to providing and maintaining the highest standards of the nursery and landscape industry.
Our goal is to provide functional and creative landscape designs backed by experienced installation specialists and qualified maintenance personnel.
We use hardy nursery stock grown by some of the finest nurseries in the Midwest . Our construction materials are provided by a select group of suppliers and dealers all of whom carry standards meeting and/or exceeding industry specifications.
The products and services we provide are backed by our written guarantee You should expect complete satisfaction from your project. It is our hope to earn your respect and repeat business through hard work and dedication to our trade. We look forward to serving you.
QUALITY CONTROLAll materials are guaranteed to be as specified in the quantities listed. Substitutions of similar appearance and value will be made at the discretion of the contractor wih permission of the owner should the availability of plant or construction materials substantially delay or prevent timely completion of a job. All work is guaranteed and performed in a manner meeting or exceeding manufacturer specifications and installation procedures.
Any significant alterations or deviations from the approved design requiring changes in costs will be executed only upon proper authorization and will be charged accordingly with respect to the contracted price. All agreements are contingent upon accidents, adverse weather conditions, availability of specified materials and delays beyond our control.
We do our bests to install on a first come first serve basis. Please be patient with us as landscaping in our area is a dynamic business with many variables i.e. weather, change orders, personnel requirements, etc. These variables may add significant time to a project. We try to update our clients to the status of their installation. Please understand we will do our best to install your project when you are told, but changes do occur which may delay a project as little as a day or two and on occasion up to a week or more.
Ziegler's Landscape By Design carries general liability and Workmen's Compensation Insurance.
Homeowners are responsible for insurance to cover fire, theft, wind damage, flooding, and vandalism.
PLANT GUARANTEEWe will guarantee your plants for 1 month from installation. We promise to give you healthy plant material. It is up to you to give the plants proper care after we leave your site. Keep an eye on your new plants and make sure to properly water them!
All claims and losses must be reported within the guarantee period and confirmed by an authorized representative of Ziegler's Landscape By Design Replacement plants are not guaranteed . We will not replace plants killed by rodents, insects, mechanical damage, owner neglect, or natural disasters. We cannot guarantee plants in pots, planter boxses, annual lowers, non hardy perennials, seeds, bulbs, azaleas, rhododendrons, roses, or any plant which may have been transplanted on the owners property or is not listed as hardy to Zone 4. There will by no guarantee for plants, materials, or labor with Jobs not paid in full by the contracted date.
We use only the finest bluegrass sod and seed varieties available, however, we cannot control the weather, soil conditions or subsequent care and watering all of which determine the ultimate success or failure of a lawn. Sod and seed is guaranteed viable upon the day of installation only.